当前位置:9136范文网>实用文档>合同>英文合同

英文合同

时间:2023-04-29 15:57:03 合同 我要投稿

关于英文合同模板9篇

  在人们越来越相信法律的社会中,关于合同的利益纠纷越来越多,它也是实现专业化合作的纽带。那么制定合同书有什么需要注意的呢?以下是小编整理的英文合同9篇,仅供参考,大家一起来看看吧。

关于英文合同模板9篇

英文合同 篇1

  销 售 合 同

  SALES CONTRACT

  编号:Contract No:日期: Date:

  签约地点:Signed at:

  卖方:Sellers:

  地址:Address:

  邮政编码:Postal Code:

  电话:Tel: 传真:Fax:

  买方:Buyers:

  地址:Address:

  邮政编码:Postal Code:

  电话:Tel: 传真:Fax:

  兹确认售予买方下列货品,其成交条款如下:

  The Seller hereby confirms selling the following goods on terms and conditions

  (3)公差:数量及总值均有_____%的增减,由卖方决定

  Tolerance: With _____% more or less both in amount and quantity allowed at the

  sellers option.

  (4) 原产地

  Country of Origin:

  (5) 付款方式:30%预付,70%发货前一周付清

  Payment terms: 30% deposit, 70% payment within one week before delivery.

  (6) 交货时间:收到预付款后15天内完成装运。

  Time of shipment: Within15 days after deposit received.

  (7) 贸易方式:FOBShanghai

  Terms of Shipment: FOBShanghai

  (8) 包装:胶合板木盘外封铁皮

  Packing: Plywood drum with steel sheet cover.

  (9) 保险:由卖方按发票全额110%投保至_____为止的_____险。

  Insurance: To be effected by seller for 110% of full invoice value covering _____ up to _____ only.

  (10) 装运口岸:中国上海港

  Port of Loading: Shanghai Port, China

  (11) 转运:允许

  Transshipment: Allowed

  (12) 分批装运:允许分批装运

  Partial Shipment: Allowed

  (13) 目的口岸:

  Port of Destination:

  (14) 唛头:Shipping Marks:

  (15) 单据:Documents:

  (16) 品质与数量、重量的异义与索赔:Quality/Quantity Discrepancy and Claim:

  (17) 逾期发运:如果由于买方原因造成逾期发运,买方承担责任。造成自签订合同之日起超过45天不能发运的,卖方将每日按货物金额的3%收取保管费;如果由于买方原因造成逾期发运超过6个月,卖方有权自行处置定金和货物。如果是卖方原因造成的逾期发运,卖方需提前告知买方并得到买方的确认并承担其他相关费用。

  LAST SHIPMENT: if the late delivery is caused by the buyer, the buyer shall bear the

  responsibility. If the delay has being made more than 45 days from the signing of the Sales Contract hereof, the buyer shall pay 3% of total amount each day, and if the delay is more than 6 months, the Seller has the right to dispose the down payment and the goods. If the late delivery is caused by the Seller, the Seller shall inform the Buyer in advance and get confirmation from the Buyer, and the related expense shall be born by the Seller.

  (18) 质量/数量异议:对于质量方面的异议,买方必须在货物抵达目的港后30天之类提出:对于数量方面的异议,买方必须在货物抵达目的港后15天之内提出。对由于保险公司、运输公司、其他运输机构或邮局的原因所造成的货物差异,卖方不负任何责任。 QUALITY/QUANTITY DISCREPANCY: In case of quality discrepancy, claim shall be filed by the Buyer within 30 days after the arrival of the goods at port of destination; while for quantity discrepancy, claim shall be filed by the buyer within 15 days after the arrival of the goods at port of destination. It is understood that the Seller shall not be liable, for any discrepancy of goods shipped due to causes for which the Insurance Company, Shipping Company, other transportation organization or Post Office are liable.

  (19) 不可抗力:卖方对由于下列原因而导致不能或暂时不能履行全部或部分合同义务的,不负责任:水灾、火灾、地震、干旱、战争或其他任何在签约时卖方不能预料、无法控制且不能避免和克服的事件。但卖方因尽快地将所发生的事件通知对方,并应在事件发生后15天内将有关机构出具的不可抗力事件的证明寄交对方。如果不可抗力事件之影响超过120天,双方应协商合同继续履行或终止履行的`事宜。

  FORCE MAJEURE: Seller shall not be responsible for failure or delay in performance of entire or portion of these Sale Contract obligations in consequence of Force Majeure incidents: flood, fire, earthquake, drought, war, or any other matters couldn’t be foreseen or controlled or couldn’t be avoided. But Seller shall inform the incidents to Buyer immediately, and shall delivery the certificate of Force Majeure incidents issued by related organization within 15 days after the incidents happened. If the incidents influence more than 120 days, both parties shall negotiate to decide whether to execute or terminate the Sales Contract.

  (20) 仲裁:因履行本合同所发生的一切争议,双方应友好协商解决,如协商仍不能解决争议,则应将争议提交中国国际经济贸易仲裁委员会(北京),依据其仲裁规则仲裁。仲裁裁决是终局的,对双方都有约束力。仲裁费应由败诉一方承担,但仲裁委员会另有裁定的除外。在仲裁期间,除仲裁部分之外的其他合同条款应继续执行。

  ARBITRATION: All disputes across from the execution of, or in connection with this Sales Contract shall be settled friendly through negotiation, in case no settlement can be reached, the case shall then be submitted to China International Economic and

  Trade Arbitration Commission, Beijing for arbitration in accordance with its provisional rules of procedure. The result of arbitration shall be born by the losing party except for the condition the Commission has other judgment. During the arbitration period, clauses beside of the arbitrated parts shall be executed.

  (21) 本合同为中英文对应,一式两份,买卖双方各执一份;合同自卖方签字盖章、买方签字后生效(传真件以及扫描具有正版相等法律效应)。

  The Sales Contract is concluded in Chinese and English with same effectiveness, and will come into effect on stamp of Seller and signing by Buyer. The Sales Contract is in dual original and each party shall have one original copy of this Sales Contract. (Any scanned and faxed copy shall have the same legal effect as the original one.)

  (22) 备注:Remark:

  买方确认签署: 卖方确认签署:

  For and on behalf of Buyer:For and on behalf of Seller:

英文合同 篇2

  编号:

  Contract No:

  日期:

  Date:

  签约地点:

  Signed at:

  卖方:

  Sellers:

  地址:

  Address:

  邮政编码:

  Postal Code:

  电话:

  Tel:

  传真:

  Fax:

  买方:

  Buyers:

  地址:

  Address:

  邮政编码:

  Postal Code:

  电话:

  Tel: 传真:

  Fax:

  兹确认售予买方下列货品,其成交条款如下:

  The Seller hereby confirms selling the following goods on terms and conditions

  (1)公差:数量及总值均有_____%的增减,由卖方决定

  Tolerance: With _____% more or less both in amount and quantity allowed at the

  sellers option.

  (2) 原产地

  Country of Origin:

  (3) 付款方式:30%预付,70%发货前一周付清.

  Payment terms: 30% deposit, 70% payment within one week before delivery.

  (4) 交货时间:收到预付款后15天内完成装运。

  Time of shipment: Within15 days after deposit received.

  (5) 贸易方式:FOB Shanghai

  Terms of Shipment: FOB Shanghai

  (6) 包装:胶合板木盘外封铁皮

  Packing: Plywood drum with steel sheet cover.

  (7) 保险:由卖方按发票全额110%投保至_____为止的_____险。

  Insurance: To be effected by seller for 110% of full invoice value covering _____ up to _____ only.

  (8) 装运口岸:中国上海港

  Port of Loading: Shanghai Port, China

  (9) 转运:允许

  Transshipment: Allowed

  (10 分批装运:允许分批装运

  Partial Shipment: Allowed

  (11) 目的口岸:

  Port of Destination:

  (12) 唛头:Shipping Marks:

  (13) 单据:Documents:

  (14) 品质与数量、重量的异义与索赔:Quality/Quantity Discrepancy and Claim:

  (15) 逾期发运:如果由于买方原因造成逾期发运,买方承担责任。造成自签订合同之日起超过45天不能发运的,卖方将每日按货物金额的3%收取保管费;如果由于买方原因造成逾期发运超过6个月,卖方有权自行处置定金和货物。如果是卖方原因造成的逾期发运,卖方需提前告知买方并得到买方的确认并承担其他相关费用。

  LAST SHIPMENT: if the late delivery is caused by the buyer, the buyer shall bear the

  responsibility. If the delay has being made more than 45 days from the signing of the Sales Contract hereof, the buyer shall pay 3% of total amount each day, and if the delay is more than 6 months, the Seller has the right to dispose the down payment and the goods. If the late delivery is caused by the Seller, the Seller shall inform the Buyer in advance and get confirmation from the Buyer, and the related expense shall be born by the Seller.

  (16) 质量/数量异议:对于质量方面的异议,买方必须在货物抵达目的港后30天之类提出:对于数量方面的异议,买方必须在货物抵达目的港后15天之内提出。对由于保险公司、运输公司、其他运输机构或邮局的.原因所造成的货物差异,卖方不负任何责任。 QUALITY/QUANTITY DISCREPANCY: In case of quality discrepancy, claim shall be filed by the Buyer within 30 days after the arrival of the goods at port of destination; while for quantity discrepancy, claim shall be filed by the buyer within 15 days after the arrival of the goods at port of destination. It is understood that the Seller shall not be liable, for any discrepancy of goods shipped due to causes for which the Insurance Company, Shipping Company, other transportation organization or Post Office are liable.

  (17) 不可抗力:卖方对由于下列原因而导致不能或暂时不能履行全部或部分合同义务的,不负责任:水灾、火灾、地震、干旱、战争或其他任何在签约时卖方不能预料、无法控制且不能避免和克服的事件。但卖方因尽快地将所发生的事件通知对方,并应在事件发生后15天内将有关机构出具的不可抗力事件的证明寄交对方。如果不可抗力事件之影响超过120天,双方应协商合同继续履行或终止履行的事宜。

  FORCE MAJEURE: Seller shall not be responsible for failure or delay in performance of entire or portion of these Sale Contract obligations in consequence of Force Majeure incidents: flood, fire, earthquake, drought, war, or any other matters couldn’t be foreseen or controlled or couldn’t be avoided. But Seller shall inform the incidents to Buyer immediately, and shall delivery the certificate of Force Majeure incidents issued by related organization within 15 days after the incidents happened. If the incidents influence more than 120 days, both parties shall negotiate to decide whether to execute or terminate the Sales Contract.

  (18) 仲裁:因履行本合同所发生的一切争议,双方应友好协商解决,如协商仍不能解决争议,则应将争议提交中国国际经济贸易仲裁委员会(北京),依据其仲裁规则仲裁。仲裁裁决是终局的,对双方都有约束力。仲裁费应由败诉一方承担,但仲裁委员会另有裁定的除外。在仲裁期间,除仲裁部分之外的其他合同条款应继续执行。

  ARBITRATION: All disputes across from the execution of, or in connection with this Sales Contract shall be settled friendly through negotiation, in case no settlement can be reached, the case shall then be submitted to China International Economic and

  Trade Arbitration Commission, Beijing for arbitration in accordance with its provisional rules of procedure. The result of arbitration shall be born by the losing party except for the condition the Commission has other judgment. During the arbitration period, clauses beside of the arbitrated parts shall be executed.

  (19) 本合同为中英文对应,一式两份,买卖双方各执一份;合同自卖方签字盖章、买方签字后生效(传真件以及扫描具有正版相等法律效应)。

  The Sales Contract is concluded in Chinese and English with same effectiveness, and will come into effect on stamp of Seller and signing by Buyer. The Sales Contract is in dual original and each party shall have one original copy of this Sales Contract. (Any scanned and faxed copy shall have the same legal effect as the original one.)

  (20) 备注:

Remark:

  买方确认签署: 卖方确认签署:

  For and on behalf of Buyer: For and on behalf of Seller:

英文合同 篇3

  买 方: (The ;Buyers)

  卖方: (The Sellers)

  兹经买卖双方同意按照以下条款由买方购进,卖方售出以下商品:

  This contract is made by and between the Buyers and the Sellers; whereby the Buyers agree to buy and the Sellers agree to sell the under-mentioned goods subject to the terms and conditions as stipulated hereinafter:

  (1) 商品名称:

  Name of Commodity:

  (2) 数 量: Quantity:

  (3) 单 价: Unit price:

  (4) 总 值: Total Value:

  (5) 包 装: Packing:

  (6) 生产国别: Country of Origin :

  (7) 支付条款: Terms of Payment:

  (8) 保 险: insurance:

  (9) 装运期限: Time of Shipment:

  (10) 起 运 港: Port of Lading:

  (11) 目 的 港: Port of Destination:

  (12)索赔:在货到目的口岸45天内如发现货物品质,规格和数量与合同不附,除属保险公司或船方责任外,买方有权凭中国商检出具的检验证书或有关文件向卖方索赔换货或赔款。

  Claims:

  Within 45 days after the arrival of the goods at the destination, should the quality, Specifications or quantity be found not in conformity with the stipulations of the contract except those claims for which the insurance company or the owners of the vessel are liable, the Buyers shall, have the right on the strength of the inspection certificate issued by the C.C.I.C and the relative documents to claim for compensation to the Sellers

  (13)不可抗力:由于人力不可抗力的原由发生在制造,装载或运输的过程中导致卖方延期交货或不能交货者,卖方可免除责任,在不可抗力发生后,卖方须立即电告买方及在14天内以空邮方式向买方提供事故发生的证明文件,在上述情况下,卖方仍须负责采取措施尽快发货。

  Force Majeure :

  The sellers shall not be held responsible for the delay in shipment or non-deli-very of the goods due to Force Majeure, which might occur during the process of manufacturing or in the course of loading or transit. The sellers shall advise the Buyers immediately of the occurrence mentioned above the within fourteen days there after . the Sellers shall send by airmail to the Buyers for their acceptancea certificate of the accident. Under such circumstances the Sellers, however, are still under the obligation to take all necessary measures to hasten the deliveryof the goods.

  (14)仲裁:凡有关执行合同所发生的一切争议应通过友好协商解决,如协商不能解决,则将分歧提交中国国际贸易促进委员会按有关仲裁程序进行仲裁,仲裁将是终局的,双方均受其约束,仲裁费用由败诉方承担。

  Arbitration :

  All disputes in connection with the execution of this Contract shall be settled friendly through negotiation. in case no settlement can be reached, the case then may be submitted for arbitration to the Arbitration Commission of the China Council for the Promotion of International Trade in accordance with the Provisional Rules of Procedure promulgated by the said Arbitration Commission . the Arbitration committee shall be final and binding upon both parties. and the Arbitration fee shall be borne by the losing parties.

  买方: 卖方:

  (授权签字) (授权签字)

  【拓展延伸】

  1.前言 Preamble

  一份标准英文合同通常可以分为前言(Preamble)、正文(Operative part)、附录(Schedule)及证明部分即结束词(Attestation)四大部分组成。

  前言(Preamble)由“Parties”及“Recitals”两部分组成。

  “Parties”为必备条款,在很多时候称为“commencement”即合同的开场白,主要介绍合同各方的名称或姓名、注册地及地址、邮编及在合同中的简称。当然,并不是所有的合同都要详细介绍以上诸要素,在许多简单合同中,只是提一下各方的名称。

  I. 以下为“Parties”的常用表达方式:

  1. This Agreement is entered into by and between ____ and ____.

  本协议由以下双方____和___ 签署。

  2. This Agreement is entered into by and between ____ (hereinafter referred to as____) and ____ (hereinafter referred to as "_____"), whereby it is agreed as follows:

  本协议由以下双方____(以下简称____)和_____(以下简称___)签署,达成如下协议:

  注:在很多合同中,这部分加入签约事由,如:

  This Agreement is entered into through friendly negotiations between _____ Co.

  (hereinafter referred to as the “Party A”) and _____ Co. (hereinafter referred to as the “Party B”) based on equality and mutual benefit to develop business on the terms and conditions set forth below:

  本协议由_____(以下称为甲方)和____(以下称为乙方)为发展业务在平等互利的基础上签订,其条款如下:

  This Agreement is entered into between _____ (hereinafter referred to as "Company"), and ______, (hereinafter referred to as "Employee") pursuant to paragraph VIII(2) of the Employee Handbook, whereby it is agreed as follows:

  本“协议”由_____(以下简称“公司”)与_____(以下简称“雇员”)根据“雇员手册”第VIII(2)款签署,“协议”内容如下:

  II. 以下为标准的“Parties”条款:

  3. This Agreement is made and entered into this _____th day of _____ in the year of ____ by and between ______, a company duly organized and existing under and by virtue of the laws of ______, with its principal place of business at _____ (hereinafter referred to as “_____”), and ______, a company duly organized and existing under and by virtue of the laws of _____, with its principal place of business at _____ (hereinafter referred to as “_____”), whereby it is agreed as follows:

  本合约由______,在_____法律之下并凭该等法律正式组织并存在的公司,其主要营业地点在______(下称_____),与_____,在_____法律之下并凭该等法律正式组织并存在的公司,其主要营业地点______(下称代理人),于_____日签订和缔结,协议如下:

  III. “Recitals” 由数个以"Whereas"字样开头的句子所组合而成(这些句子俗称为“Whereas Clauses”),表示当事人乃是在基于对这些事实(例如订约的目的、背景来由等)的共同认识,订立此合约。

  4. This Agreement is made and entered into this _____ day of _____ in the year of ____ by and between _______, a company duly organized and existing under and by virtue of the laws of ______, with its principal place of business at ______ (hereinafter referred to as “_____”), and ______, a company duly organized and existing under and by virtue of the laws of ______, with its principal place of business at ______ (hereinafter referred

  to as “_____”)

  WITNESSED

  WHEREAS, NOW THEREFORE, the parties hereto agree as follows:

  本合约由_____,在_____法律之下并凭该等法律正式组织并存在的公司,其主要营业地点在______(下称_____)(或下称供应商),与_______,在_____法律之下并凭该等法律正式组织并存在的公司,其主要营业地点_

  鉴于

  因此,双方当事人达成以下协议:

  注:WITNESSED可以用WITHNESSTH、WITHNESSTH THAT等来代替。

  IV. 在很多美国常用合同中,在很多情况下直接用RECITALS引导数个陈述语句或“Whereas Clauses”。下面为一个资产购买协议实例:

  This ASSET PURCHASE AGREEMENT (the "Agreement") is made and entered into as of May 19, 1997 by and among AAA, a Delaware corporation ("AAA"), BBB, a Delaware corporation and wholly-owned subsidiary of AAA ("Buyer"), CCC ("Summit"), and DDD, an Oregon corporation and wholly-owned subsidiary of Summit ("Seller").

  RECITALS

  A. The Boards of Directors of each of Summit, Seller, AAA and Buyer believe it is in the best interests of each company and their respective security holders that Buyer acquire certain listed assets and assume certain listed liabilities of Seller (the "Acquisition").

  B. On the date hereof, Buyer has executed a $2,000,000 irrevocable purchase order to purchase 400 time-based licenses for Summit's Visual HDL interfaces for Visual Test bench ("VTB") software on AAA's standard form of purchase order, which is payable within five (5) business days after the date hereof.

  NOW, THEREFORE, in consideration of the covenants, promises and representations set forth herein, and for other good and valuable consideration, the parties agree as follows:

  2. 定义 Definition

  在正文(Habendum)部分,通常第一章为定义(Definitions)部分。

  定义条款即对合同中涉及的术语及名词作出限定、解释的条款。它可以散见于合同各个部分,但对于一些大型的、重要的合同,通常将其置于第一章。

  I. 常见的定义语句常用mean, refer to, be construed as, include等来表达。如:

  1. "Territory" means the United States of America.“销售地区”是指美利坚合众国。

  2. “Commencement date” shall mean the date of signing this agreement by the last signing party hereto.

  “协议生效日”是指本“协议”最后签字的一方签署本“协议”的日期。

  3. The “agreement” herein referred to shall mean this agreement of agency by entrustment.

  “协议”在这里是指本委托代理协议。

  4. “Code” shall refer to the current and applicable Internal Revenue Code.

  “法”是指当前可用的国内税收法。

  5. Reference to any statutory provision shall be construed as a reference to the same as it may have been, or may from time be, amended, modified or re-enacted.

  引用法律规定理解为引用其本身外,还包括其修订、修正或重新实施案。

  6. "Expenses" include costs, charges and expenses of every description.

  “费用”包括各种形式的金钱支出。

  II. 还有一类特殊的定义语句,即对于「单、复数」及「阴、阳性」名词的范围定义。通常都是用include来表达:

  1. "Stock Certificate" includes "stock certificate" and "stock certificates".

  合同中的“股票”,包括单数与复数。

  2. "He" includes "he" and "she".

  合同中的“他”,包括“他”与“她”。

  3. Words using the singular or plural number also include the plural or singular number.

  采用单数或复数的单词也包括复数或单数。

  III. 定义语句中,有时需限定范围。而通常用得最多的是:“for the purpose of ”及“in relation to” 某概念的定义条款,如果适用范围仅限于合同的“特定部份”,可以用“for the purpose of ”来为定义条款起头。而如果定义条款是针对合同的“特定概念”,就用“in relation to”来界定。如下例:

  1. For the purpose of this Agreement, "Products" means all types of the machineries manufactured by Manufacturer as are specified in Attachment A hereto.

  本协议所称的“产品”,指制造人所制造如附件A表列之各式机器。

  2. "Address" means-

  (a) 就自然人而言in relation to an individual, his usual residential or business address; and

  (b) in relation to a corporation, its registered or principal office in the Republic of China.

  “地址”就自然人而言,指通常之居所或工作场所;就公司而言,指位于中华人民共和国之注册所在地或主营业所。

  IV. 在定义条款中,在定义语句前有时会加上一些陈述语句来引导,如:

  1. For the purpose of this Agreement, each of the following terms shall have the following meaning respectively:

  就本合同的目的而言,下列各用语,分别具有下述意义:

  2. In this Agreement, the following words or expressions shall have the meanings given to them respectively below:

  本协议内所用词句的意义,明确阐述如下:

  3. In this agreement unless the context otherwise requires, the following words and expressions shall have the meanings assigned to them hereunder:

  除非本“协议”有明确规定,下列词语应当具有如下规定之意义:

  4. The following are the definitions of various terms used in this Agreement:

  本“协议”使用之术语定义如下:

  3. 有效期 Period of validity

  有效期(Term)条款通常规定合同的有效期限,何时生效及到何时结束,合同结束后必要时如何延展等等。

  I. 以下为“Term”的常用表达方式:

  The term of this contract is for a _____ year period.合同的有效期为_____年。

  如:The term of this contract is for a one (1) year period.

  2. The contract is for a _____ month period, commencing _____.

  合同的有效期为_____月,开始于______。(期限)

  a. The contract is for a 12 month period, commencing September 17, 20xx thru September 16, 20xx.

  b. The contract is for a 6 month period, commencing 4-1-03 and ending 9-30-20xx.

  3. This agreement remains valid for _____ year(s), i.e. commencing on ______, _____and terminating on ______, _____.

  本协议在_____年之内有效,即从_____年_____月_____日起生效,_____年_____月_____日起到期。

  4. The contract term is hereby extended for the period____.

  合同的有效期为_______。

  如:The contract term is hereby extended for the period____ in accordance with Section E, Paragraph 10, Term of Contract and Contract Extension.

  II. Term条款除了规定合同的期限外,通常另外合同期限的延展“Extension”。

  1. The contract period is for _____ year with option to re-new for _____ year.

  合同有效期为_____年,同时可以选择延长_____年。

  2. The contract is for a _____ month period, commencing _____. The contract may be renewed for up to _____ year option periods.

  合同的有效期为_____月,开始于_______,同时可以选择延长_____年。

  3. This agreement shall commence on the commencement date and shall endure for a continuous period of _____ years. Thereafter it will be automatically renewed for successive periods of _____ years on the same terms and conditions unless one of the parties had given _____days notice of termination.

  本协议应自生效日生效并在_____年内有效。此后,除非一方当事人提前_____天书面通知对方当事人终止本协议,本协议有效期自动延长_____年,协议条款不变。

  III. Term条款并没有十分固定的表达方式,以下即是一些合同中Term的实例:

  1. This Agreement shall be valid and remain in force for a period of three (3) years commencing from the date appearing first above written upon the signing of both Party A and Party B and shall be extended for another period of three (3) years on the same terms and conditions unless either of the parties hereto gives the other party at least thirty (30) days prior written notice to terminate this Agreement prior to the expiration of the original term.

  本合约须从上面首次写明的甲方和乙方签订本约的日期起生效并保持效力三年,并将按同样条件延长三年,否则与约任何一方至少须在原定时间期满前三十天给予另一方提前终止本合约的书面通知。

  2. At any time and from time to time during the period commencing on the date hereof and terminating on ______, 20___, party A may in writing advise party B.

  自本协议签订之日起到______年______月协议终止这段期间内,甲方可随时以书面形式通知乙方。

  3. The term of this Agreement shall be three years from the effective date, unless terminated in accordance with Article VI- (3) and Article IX.

  本合同的期限除非根据第8条第3款及第9条的规定终止外,有效期为3年。

  4. The contract is valid from _______ until _______.

  The contract period is automatically extended for any leave of absence allowed for in law.

  合同的有效期为从______到_____。

  5. The term of this Agreement shall commence on the _____ day of _____ and end on the _____ day of _____ Upon expiration of the above initial term, this Agreement shall automatically be renew and extended for a like period of time unless terminated in writing by either party _____ days prior to the date for such renewal.

  本协议期限为__年____月____日至__年___月___日。除非续订日前_____天一方以书面方式提出终止,否则上述首期届满后,协议应自动续订,延长时间与前期相同。

  4. 不可抗力 Force Majeure

  Force Majeure条款是一种免责条款,即免除由于不可抗力事件而违约的一方的违约责任。一般应规定的.内容包括:不可抗力事件的定义(Definition of Force Majeure)以及不可抗力事件的后果(Consequences of Force Majeure) 。在Force Majeure条款中,两者属于因果关系,难以截然分开。

  I. 对于Force Majeure的定义,《合同法》定义如下:

  本法所称不可抗力,是指不能预见、不能避免并不能克服的客观情况。

  For purposes of this Law, force majeure means any objective circumstance, which is unforeseeable, unavoidable and insurmountable.

  II. 以下是Force Majeure条款的举例:

  1. Neither party shall be responsible for delays or failures in performance resulting from acts or facts reasonably beyond the control of that party.

  任何一方不应对因其无法控制之行为或事实造成协议延迟履行或不履行承担任何责任。

  2. Either Party shall not be liable for any delay caused by any unpredictable factor or any factor which is unavoidable or insurmountable by reasonable means at the time of conclusion of this Agreement, or any loss caused by failure in fulfillment of obligations as stipulated herein.

  协议任一方无须对因任何在本协议签订时无法预见或以合理手段也无法避免或克服之原因造成的迟延或不履行本协议之义务所造成的损失承担责任。

  注:以上采用的是类似《合同法》概括的定义方法。而合同为不可抗力定义时更多地采用列举的方法。

  3. Neither party of this Agreement, directly or indirectly owing to any causes or circumstances beyond its control, including Acts of God, Governmental orders or restriction, war, warlike conditions, revolutions, strike, lockout, fire and flood.

  本合同任何一方当事人对直接或间接地由于其无法控制的原因或情况包括自然灾害、政府命令或限制、战争、战争状态、革命、罢工、工厂被关闭、火灾、水灾等而未能履行或延迟履行合同或合同一部分的行为,不负任何责任。

  注: Acts of God通常也译为“不可抗力”,但主要是指自然灾害;而Force Majeure则包括自然及人为两方面。

  4. Neither party will be liable for nondelivery, misdelivery or late delivery (other than the payment of money due hereunder) caused by circumstances beyond its reasonable control, including, among others, war, civil strife or commotion, riots, strikes, fires, floods, acts of God, inability to obtain materials, failure of carriers or compliance with any law, regulation or governmental order.

  任何当事人将不会为任何因为不可控制的情况产生的未交付货物、交付错误或延迟交货(除了支付应付款)。不可控制的情况包括战争、国内斗争或*乱、骚乱、罢工、火灾、洪灾、自然灾害、无力获得材料、承运人的失误、遵守法律、法规或政府令。

  5. Should either of the parties to the contract by prevented from executing the contract by force majeure, such as earthquake, typhoon, flood, fire and war and other unforeseen events, and their happening and consequences are unpreventable and unavoidable, the prevented party shall notify the other party by cable without any delay, and within 15 days thereafter provide the detailed information of the events and a valid document for evidence issued by the relevant public notary organization

  for explaining the reason of its inability to execute or delay the execution of all or part of the contract. Both parties shall, through consolations, decide whether to terminate the contract or to exempt the part of obligations for implementation of the contract or whether to delay the execution of the contract according to the effects of the events on the performance of the contract.

  由 于地震、台风、水灾、火灾、战争以及其它不能预见并且对其发生和后果不能防止或避免的不可抗力事件出现,致使直接影响合同的履行或者不能按约定的条件履行 时,遇有上述不可抗力的一方,应立即电报通知对方,并应在十五天内,提供不可抗力详情及合同不能履行、或者部分不履行、或者需要延期履行的理由的有效证明 文件。此项证明文件应由事故发生地有权证明的机构出具。按其对履行合同影响的程度,由双方协商决定是否解除合同,或者部分履行合同,或者延期履行合同。

  6. Force majeure shall hereof consist of the following events:

  下述事件构成不可抗力:

  Where such cases as war, earthquake, serious windstorms, snow, or fire or other events which no party can foresee and prevent from happening occur;

  发生战争、地震、严重的风灾、雪灾、火灾或其他各方无法预见、无法抗拒的事故。

  The related laws and regulations in collection with the execution of duties by any party to this Agreement undergo changes, under which this Agreement will be illegal or the transfer cannot be fulfilled.

  自本协议签订之日起与本协议任何一方履行本协议相关的法律、法规发生变更致使本协议非法或转让行为无法完成。

  In event of the occurrence of the above-mentioned events, if any party (hereinafter referred to as the “Effected Party ”) has been delayed or deterred from performing the duties of this Agreement in the course of its execution, the Affected Party shall be free from any liabilities for breach of the agreement and for compensation.

  在发生本协议不可抗力事件之后,任何一方(以下简称受影响方)在履行本协议义务时受到拖延或不能履行时,受影响方不承担任何违约责任及赔偿责任。

  In event of the force majeure, the affected party shall, within _____days from the date of the occurrence, notify the other party of the impact of such events on the execution of the duties in this Agreement, by telex, telegraph or in any other lawful written form, and simultaneously submit the relevant official credentials concerning the force majeure herein.

  在发生不可抗力事件时,受影响方应自不可抗力事件发生之日起_____天内以电传或电报或其他任何合理书面方式,通知另一方有关不可抗力的发生和不可抗力对其履行本协议的义务的影响,同时应呈交不可抗力的有关官方证明。

  Should the effect of the force majeure cases last more than _____ days, both parties shall consult each other about the alterations of this Agreement; in case they fail to reach an agreement, Chapter 8 shall thereupon apply.

  在不可抗力事件延续_____天后,双方必须磋商本协议的变更,双方未能协商一致的,适用本协议第八章的规定。

  7. Force Majeure不可抗力

  (1) No party to this Contract shall be liable to the other party for any failure of or delay in performance of its obligations hereof nor be deemed to be in breach of this Contract, if such failure or delay has arisen from "force majeure."

  如果任何一方因不可抗力而款能履行或推迟履行其义务,则不对另一方负责,也不应视作违反合同。

  "Force Majeure" means circumstances and conditions beyond the control of either parties, that would render it impossible for either the Owner or the Contractor to fulfill their obligations under this Contract, or delay such fulfillment. Any of the following matters are considered "force majeure."

  “不可抗力”指业主或承包商无法控制的情况,使当事人未能按本合同履行其义务,或者不得不延迟履行其义务。下列情况均被视作“不可抗力”:

  a. war, hostilities, act of foreign enemy, invasion, warlike opera-tions (whether war to be declared or not) or civil war;

  b. mutiny, civil commotion assuming the proportions of or amounting to a popular rising, military rising, insurrection, rebellion, revolution, military or usurped power, or any act of any person acting on behalf of or in connection with any organization with activities directed towards the overthrow by force of the Government de jure or de facto, or to the influencing of it by terrorism or violence;

  c. earthquake, flood, fire or other natural physical disaster;

  d. denial of the use of all ports, airports, shipping services or other means of public transport;

  e. strike or lock out or other industrial concerted action by workers, affecting the fulfillment of Contractor's and subcontractors' obligations;

  f. and other unforeseen circumstances beyond the control of the parties so affected rendering the fulfillment of their obligations impossible.

  a. 战争、敌对事件、外敌行动、入侵、类似战争的军事行动(不管是事宣战)、内战;

  b. 士兵哗变、民众*乱、军事叛乱、起义、造反、革命、篡权、或者任何个人代表某个组织或与某个组织有联系、旨在以暴力推翻合法或现存政府、或以恐怖主义或暴力对政府施加影响的行为;

  c. 地震、洪水、火灾或其他自然灾害;

  d. 所有港口、机场、船运或其他公共交通工具的使用均遭拒绝;

  e. 工人罢工、工厂停工、或其他的劳工联合行动,影响了承包商和分包商履行其义务;

  f. 当事人无法控制、从而使其不能履行义务的其他任何意外情况。

  (3) If either party to this Contract is prevented or delayed from or in performing any of his obligations under this Contract by force majeure, then he may notify the other party of the circumstances constituting the force majeure and of the obligation performance of which is thereby delayed or prevented and the party giving the notice shall thereupon be excused from the performance or punctual performance, as the case may be, of such obligation for so long as the circumstances of prevention or delay may continue.

  如果本合同任何一方因不可抗力不能或延迟履行本合同规定的任何义务,他可将不可抗力和由此造成的延迟或妨碍情况通知另一方。发出通知的一方允许根据具体情况及妨碍或延迟持续的时间免于履行或推迟履行合同。

  (4) If by virtue of the preceding sub-clause dither party shall be excused from the performance or punctual performance of any obligation for a continuous period of ________ months, then either party may at any time thereafter terminate this Contract by giving a written notice to the other party.

  根据本第款第3分条规定,如果任何一方免于履行或推迟履行其义务的时间持续了____个月,那么任何一方都可随时向另一方发出书面通知,终止本合同。

  5. 修改 Modification

  合同修订 (Modification)条款为合同常用条款.主要规定了合同修订的方式与途径。例如:书面合同,只能以书面方式进行修订,口头修订内容无效。

  I. Modification条款通常较为简单,以下为一些常用比较简约的表达方式:

  1. The contract can be amended only after the amendment is agreed upon by both parties.

  只有经双方一致同意,合同方可变更。

  2. This Agreement may be amended only by a written instrument signed by duly authorized representatives of both parties.

  本合同只有经双方当事人授权的代表正式签署的书面文件,方可修改。

  3. This Agreement may not be amended or modified except by written instrument signed

  by each of the Parties hereto.

  除非经本协议当事人签署的书面通知,否则本协议书不得作出任何修改和变更。

  4. Any alterations or amendments of this Agreement shall be subject to agreement through consultation between both parties in writing.

  本协议的任何变更或修改,应由本协议双方协商一致,并以书面方式进行。

  5. This Agreement shall not be modified or amended except by a written instrument, signed by the parties hereto.

  除非双方当事人共同签署书面文件,否则本“协议”不得修改或修订。

  6. Any modification, amendment or waiver of any of the provisions of this Agreement must otherwise be made in writing and duly signed by the parties hereto.

  对本“协议”任何规定的任何变更、修改或免责必须另以书面形式作出,并经各方正式签字。

  7. During the period of validity of the agreement, either party shall be entitled to make proposal of amendment to the agreement and the agreement amended shall go into effect with the signature of the two parties.

  在协议的有效期内,任何一方都有权提出对协议进行修改,修改后的协议经过双方签署后才能够生效。

  II. 在实际运用中,由于内容环境不同,表达可能有所不同,以下为一些实例:

  1. If the loan contract affiliated to this Contract has to be abridged, amended, or revised, both parties shall negotiate to amend and revise this Contract in line with the provisions of the loan contract.

  本股权质押项下的贷款合同如有修改、补充而影响本质押合同时,双方应协商修改、补充本质押合同,使其与股权质押项下贷款合同规定相一致。

  2. If this Contract shall be abridged, revised, or amended on account of force majeure, the responsibilities assumed by the Party A under this Contract shall not be exempted or reduced, and the rights and interests of the Party B under this Contract shall not been affected or infringed.

  如因不可抗力原因致本合同须作一定删节、修改、补充时,应不免除或减少甲方在本合同中所承担的责任,不影响或侵犯乙方在本合同项下的权益。

  3. The amendment of the contract or other appendices shall come into force only after the written agreement signed by Party A and Party B and approved by the original examination and approval authority.

  对本合同及其附件的修改必须经甲、乙双方签署书面协议,并报原审批机构批准,方可生效。

  4. This Agreement may be amended in writing signed by both Parties. Unless otherwise expressly agreed to in such amendment, all terms and conditions of this Agreement shall apply to any such addition and all rights granted to Licensee under this Agreement shall terminate as to any such deletion.

  本协议可由「双方」书面签署予以修改。除在此种修改中另行明确同意外,本协议所有的条款和条件须适用于任何此类修改中所做的添加,而所有根据本协议而给予「被许可人」的权利对于任何此类修改中的删除事项而言将终止。

  6. 补偿 Indemnification

  损害赔偿(indemnification)条款,是减少合同风险的一个重要条款。该条款主要约定在第三者对合同提出权利主张时,另一缔约方应当对此承担责任。通常情况下,另一缔约方必须支付全部的防御性诉讼费用,以及全部的支付给第三者的和解费用或者第三者胜诉后造成的所有损失。

  实际上,本条款是将第三人造成的风险从合同的一方当事人转移给另一方当事人。

  其次,本条款也可以约定合同的另一缔约方有其他不当的作为时,应当进行损害赔偿。

  I. Indemnification 条款常用“indemnify and hold harmless from……”来表达:

  1. Party A agrees to indemnify and hold Party B harmless from any claim or demand, including reasonable attorneys' fees, made by any third party due to or arising out of

  甲方同意对乙方因_____造成的损失作出赔偿及保证乙方不招致任何第三方索偿或索求,包括合理的律师费用。

  应用实例:

  Party A agrees to indemnify and hold Party B harmless from any claim or demand, including reasonable attorneys' fees, made by any third party due to or arising out of Party A's use of the Site, the violation of this Agreement by Party A, or the infringement by Party A, or other user of the Site using Party A's login name and password, of any intellectual property or other right of any person or entity.

  甲方同意对乙方因甲方使用网站、或甲方违反本协议、或因甲方或其它使用甲方之登记名称及密码而使用网站的使用者,侵犯任何知识产权或任何其它人士或单位的其它权利所造成的损失作出赔偿及保证乙方不招致任何索偿或索求,包括合理的律师费用。

  2. Party A shall indemnify and hold party B and each of party B officers, directors, stockholders, employees and agents harmless against, and in respect of, any damage, loss, liability, cost or expense, including attorneys, fees, resulting or arising from or incurred in connection with this Agreement and the transactions contemplated hereby, except such as may result from willful malfeasance if party B or such officer, director, stockholder, employee of agent, as the case may be.

  甲方应当赔偿乙方及其每个职员、董事、股东、雇员及其代理人因此协议引起或与此协议以后的交易相关事项而产生的损害、损失、责任、开支或费用,包括律师费用,但因乙方或其职员、董事、股东、雇员或代理人有意的过失而引起的损失除外。

  3. Each party will defend, indemnify and hold the other harmless from and against all actions, proceedings, claims, demands, suits, losses, damages and expenses, including reasonable attorneys fees and costs reasonably incurred in defending any proceedings in which the damages sustained arose from a failure of the other party to meet its obligations under this agreement. In no event will either party be liable to the other in connection with this agreement for special, incidental, indirect or consequential or punitive damages regardless of whether either or both parties knew of the possibility of such damages.

  一方当事人将使另一方当事人免于承担诉讼、索赔、请求、损害赔偿金及费用,包括为以下诉讼辩护而发生的合理的律师费:因另一方当事人未根据本协议履行其义务而导致损害赔偿的诉讼。

  不管一方当事人或双方当事人是否知道特殊损害赔偿、附带损害赔偿、间接损害赔偿、后果性损害赔偿、惩罚性损害赔偿发生的可能性,一方当事人均不会为另一方当事人承担上述损害赔偿。

  4. Contractor agrees to protect, defend, indemnify and hold harmless company, its parent, subsidiaries and affiliated companies, and its and their employees, subcontractors and its and their insurers from and against any claim, demand, cause of action, loss, expense award, obligation to indemnify another, judgment or liability on account of illness, injury or death to the employees of contractor and contractor’s subcontractors and/or damage to or loss or destruction of the property of contractor arising directly or indirectly out of the performance of this contract regardless of omissions or negligence, in whole or in any part, of company.

  承包商同意保护、辩护、赔偿和保证公司、其上级公司、下属公司和关联公司、及其雇员、次承包商和其保险公司不承担在履行本合同过程中,不论公司是否存在部分 或全部的不作为或疏忽的责任,直接或间接所导致的承包商和次承包商的雇员生病、受伤或死亡以及承包商的财产所遭受的毁损灭失相关的任何诉求、要求、诉因、 损失、费用、对他方的赔偿义务、判决或赔偿责任。

  II. Indemnification 条款还有多种表达方式,但并不固定。

  1. Notwithstanding any of indemnities and liabilities specifically referred to above, neither company or contractor shall be liable to the other with respect to any consequential loss including, but not limited to, loss of anticipated profit, loss of anticipated revenue, loss of anticipated production, loss of product, or loss of use of money, arising or alleged to arise out of either company’s or contractor’s failure to property carry out its obligations hereunder or due to omissions or negligence, in whole or any part, of the part at fault, its subcontractors or vendors or the un-seaworthiness of vessel, or strict liability, and regardless of whether pre-existing the execution of the agreement.

  除上列特别述及的赔偿和责任外,公司或承包商相互间不承担任何间接损失,包括但不限于预计的利润损失、预计的收益损失、预计的生产损失、产品损失、无法使用金钱的损失,由于或认为系因公司或承包商未能正确地履行本合同的义务或由于该违约系由于其次承包商或供应商(买方)或船舶不适航或严格责任和不论是否存在依以前协议履行原因,所导致的部分或全部的不作为或疏忽所造成的损失。

  2. All remedies specified herein or otherwise available shall be cumulative and in addition to any and every other remedy provided hereunder or now or hereafter available at law or in equity. No waiver or failure to act with respect to any breach or default hereunder, whether or not the other party has notice thereof, shall be deemed to be a waiver with respect to any subsequent breach or default, whether of similar or different nature.

  依据法律或衡平法,本“协议”所述的赔偿或其它可得的赔偿应当是累积的,并在本“协议”中规定的赔偿之外,或在现在或此后可得的赔偿之外。无论对方当事人通知与否,任何与违反协议或不履行协议有关的弃权不得视为与任何后来的违反协议或不履行协议有关的弃权,无论是否性质相同或不同。

  III.在大型合同中,Indemnification 条款往往非常复杂,以下即为。

  Indemnification 补偿

  (a) Each party shall indemnify and hold harmless the other party, its shareholders, directors, officers, employees, agents, designees and assignees, or any of them, from and against all losses, damages, liabilities, expenses, costs, claims, suits, demands, actions, causes of actions, proceedings, judgments, assessments, deficiencies and charges (collectively, "Damages") caused by, relating to or arising from the performance by such party in accordance with this Contract of its obligations hereunder, and Buyer shall also indemnify Seller, without limiting the foregoing, for any such item caused by, relating to or arising from (a) the programming services which are authorized for viewing sing the System, including any assertion that any such programming service involves copyright infringement, (b) any disputes between Buyer and any of its program distributors or other distributors or affiliates, (c) any disputes or claims involving the subscribers for Buyer's programming services, or (d) any assertion that Buyer has been involved in, that Buyer's conduct of subscription involves, or that Buyer's use of the System involves, any unfair competition or violations of laws, rules or regulations.

  (a)每方应就其按本合同规定履行其本合同项下义务所导致的、与其有关的或由其引发的一切损失、损害、责任、支出、费用、索赔、诉讼、要求、诉讼行为、诉因、程序、判决、估定税额、欠额以及收费(合称“损害”)补偿另一方、另一方的股东、董事、管理人员、雇员、代理、被指定人、受让人或其中任何一人,使之不受损害,并且在不对上文所述予以限制的条件下,买方还应就下述各项所导致的、与其有关的或由其引发的上述任何事项补偿卖方:

  (a)授权对viewing sing系统提供的服务;(b)买方与项目分包商、分支机构之间的纠纷;(c) 任何用户针对买方的该项目服务的纠纷或索赔;(d) 针对买方所涉该系统的不正当竞争或违法指控。

  (b) In the event of a third-party claim, with respect to which a party’s entitled to indemnification hereunder, a party (the "Indemnified Party") shall notify the other party (the "Indemnifying Party") in writing s soon as practicable, but in no event later than ______ days after receipt of such claims. The Indemnified Party's failure to provide such noticed shall not preclude it from seeking indemnification hereunder unless such failure has materially prejudiced the Indemnifying Party's ability to defend such claim. The Indemnifying Party shall promptly defend such claim with counsel of its own choosing) and the Indemnified Party shall cooperate with the Indemnifying Party in the defense of such claim, including the settlement of the matter on the basis stipulated by the indemnifying Party (with the Indemnifying Party being responsible for all costs and expenses of such settlement).

  (b)如果第三方提出一方按本合同规定有权获得补偿的索赔请求,一方(“受补偿方”)应在实际可能的情况下尽早通知另一方(“补偿方”),但无论如何不得迟于在收到该等请求后的第_______日。受补偿方未给予该通知并不排除其按本合同规定寻求补偿,除非未给予该通知补偿方抗辩该索赔请求的能力受到实质影响。补偿方(与其自行选择的律师一起)应及时对该索赔请求进行抗辩,而受补偿方应在对该索赔请求进行抗辩时与补偿方合作,包括按照补偿方规定的原则就该事项达成和解(补偿方承担该和解的一切费用与支出)。

  If the Indemnifying Party within a reasonable time after notice of a claim fails to defend the Indemnified party, the Indemnified Party shall be entitled to undertake the defense, compromise or settlement of such claim at the expense of the Indemnifying arty. Upon the assumption of the defense of such claim, the Indemnifying arty may settle, compromise or defend as it sees fit. Notwithstanding anything to the contrary set forth in this Section, seller will defend any suit, claim, action or proceeding brought against buyers to the extent that such suit, claim, action or proceeding is based on a claim that goods manufactured and sold by Seller to Buyer infringe patent, copyright, mask work, trademark, trade secret or any other intellectual property rights of any third party and Seller shall pay all damages and costs awarded by final judgment (from which no appeal may be taken) against Buyer, as well as its actual expenses and costs, on condition that Seller

  如果补偿方收到索赔通知后为受补偿方辩护,则受补偿方应有权对该索赔进行抗辩、妥协或和解,费用由补偿方承担。在承担对该等索赔请求的辩护后,补偿方可进行和解、妥协或抗辩,由其酌处。无论本条有何相反的规定,如果发生对买方的诉讼、索赔、诉讼行为或程序是基于以下主张,即卖方制造并销售给买方的物品侵犯了任何第三方的_______国专利、版权、掩模、商标、商业秘密或其他任何知识产权,则卖方将就该诉讼、索赔、诉讼行为或程序为买方辩护,并将支付局判决(不能再上诉的)判定由买方承担的损害赔偿与费用,以及买方实际的支出与费用,上述规定的条件是:

  (i) is promptly informed and furnished a copy of ach communication, notice or other action relating to the alleged infringement, (ii) is given sole control of the defense (including the right to select counsel), and the sole right to compromise and settle such suit or proceeding; provided however, that Seller's liability hereunder, if any, shall be strictly and solely limited to the amount of royalties which would be payable in respect of revenues derived by Seller from Buyer from sales of the infringing goods. Seller shall not be obligated to defend or be liable for costs and damages if the infringement arises out if a combination with, an addition to, or modification of the goods after delivery by Seller, or from use of the goods, or any part thereof, in the practice of a process.

  (1)卖方被及时告知侵权指控的发生,并得到与该侵权指控有关的每一通讯、通知或其他诉讼文书的副本,(2)得到该辩护的独家控制权(包括选择律师的权利),以及就诉讼或程序进行妥协或者和解的独家权利;但是,卖方在本合同项下的责任(如果有的话),应严格地并且仅仅限于卖方因买方销售侵权物品而应从买方获得的特许权使用费收入金额。如果侵权是由卖方交货后有人将物品混合、添加或改造而引起,或者由实施某一方法时使用物品(或其何部分)而引起,则卖方无义务进行辩护,亦无承担费用或损害赔偿的责任。

  If any goods manufactured and supplied by Seller to Buyer are held to infringe any valid patent and Buyer is enjoined from using the same, or if seller believes such infringement is likely, Seller will exert all reasonable efforts at its option and expense (i) to procure for Buyer the right to use such goods free of any liability for such infringement, or (ii) replace or modify such goods with a noninfringing substitute otherwise complying substantially with all the requirements of this contract, or (iii) upon return of the goods, refund the purchase price and the transportation costs of such goods (less reasonable allowance for their use and benefit derived therefrom for the period of time from delivery to Buyer, such allowance being based on a straight-line depreciation period of _______ years from the date of shipment by Seller).

  如果卖方制造并向买方提供的任何物品被判定侵犯有效的_______国专利,且卖方被禁止使用该专利,或者如果卖方相信很可能发生侵权,卖方将尽一切合理的努力,自费从以下措施中作出选择:(1)为买方取得使用该等物品而不产生侵权责任的权利,或(2)以在其他方面实质符合本合同所有规定的非侵权替代品来代替或改造该等物品,或(3)在该等物品被返还后,退还该等物品的购买价以及运费(扣除向买方交货至退还期间使用该等物品并从中获得利益的折扣金额,该折扣金额按从卖方装运之日起_______年直线式折旧来计算)。

  If the infringement is alleged prior to completion of delivery of the goods, Seller has the right to decline to make further shipments without being in breach of contract. If Seller has not been enjoined from selling such goods to Buyer, Seller may (at Seller's sole election), at Buyer's request, supply such goods to Buyer, in which event Buyer shall be deemed to extend to Seller the same patent indemnity hereinabove stated. The same patent indemnity shall be deemed to be extended to Seller by buyer if any suit or proceeding is brought against Seller based on a claim that the goods manufactured by Seller in compliance with Buyer's specifications infringe any valid patent. Buyer shall promptly notify Seller of any infringement by a third party of intellectual property rights licensed to Buyer under this contract. In the event that a third party infringes such intellectual property rights, the Parties shall cooperate with one another to take appropriate action to cause such infringement to cease. The foregoing states the sole and exclusive liability of the parties hereto for infringement of patents, copyrights, mask works, trade secrets trademarks, and other proprietary rights, whether direct or contributory, and is in lieu of all warranties, express, implied or statutory, in regard hereto, including, without limitation, the warranty against infringement specified in the uniform commercial code.

  如果交货完成前发生权指控,卖方有权拒绝进一步装运,而不构成违约。如果卖方还没有被禁止向买方销售该等物品,应买方请求,卖方可以(仅由卖方酌定)向买方供应该等物品,在此情况下,买方应被视为向卖方做出与本合同上文所述相同的专利补偿保证。如果有人指称卖方按照买方规格制造的物品侵犯了有效的_______国专利,并以此为根据向卖方提起诉讼或程序,则买方应被视为已向卖方做出同样的专利补偿保证。

  买方应将第三方侵犯本合同项下许可给买方的知识产权及时通知卖方。如果第三方侵犯该等知识产权,双方应互相合作,采取适当的行动制止该侵权行为。

  上文规定了本合同双方就专利、版权、掩模、商业秘密、商标以及其他专有权利的侵权(无论是直接的还是协从的)所承担的唯一责任,并且取代就其所做出的所有保证(明示的、暗示的或法定的),包括(但不限于)_____中规定的不侵权保证。

英文合同 篇4

  主合同编号(Contract NO):

  买 方(Buyer):

  地 址(Add):

  电话(Tel): 传真(Fax):

  生产厂(Producer):

  地 址(Add):

  电话(Tel): 传真(Fax):020-32915578

  为体现诚实信用的合同履行精神,防止延期交货的情况出现,双方协商一致,特制定如下条款:

  In order to reflect the spirit of good faith and for avoidance of any delay in delivery, both parties hereby agree as follows:

  一、本协议是执行主合同的关于延期交货的特别约定,主合同编号为:。

  This agreement shall constitute a special covenant for implementing the provisions of delayed delivery as set forth in the Master Contract(Contract No._______).

  二、主合同约定的`交货日期为: 年 月 日,运输方式为海运集装箱。

  Delivery date provided in the Master Contract shall be _________, and transportation mode is marine container.

  三、若生产厂无法按照上述交货期限的约定交货的,则买方有权要求改为空运方式运输,相应的空运费用约 美元(USD)从买方应当支付给生产厂的货款中扣除。(实际扣除金额以空运费单据为准)

  Where the Producer fails to deliver goods pursuant to the above delivery period, the Buyer has right to amend the original transportation mode to air transportation and corresponding air freight charge is around _______(USD) deductible from payments for goods made by the Buyer to the Producer. (actual deductible amount shall be subject to air freight receipts)

  买 方(Buyer):

  买方代表人:(签章)Representative: (Sgn & Samp)

  生产厂(Producer):

  生产厂代表人:(签章)Representative: (Sgn & Samp)

  签约时间: 年 月 日

  Date of Signing:(D-M-Y)

  注:本合同内容如有中英文翻译误差,以中文为准。

  Note: If this contract content has any error of translation, subject to Chinese.

英文合同 篇5

  一、出租人: (“甲方”)

  landlord: (part a )

  二、承租人: (“乙方”)

  tenant: (part b )

  三、租赁范围及用途:

  tenancy:

  3.1 甲方同意将其所有的位于_________________________________________的房屋在良好及可租赁的状态下租给乙方为居住使用。

  party a hereby agrees to lease its property located at

  ___________________________________in good and tenantable condition to party b for residential use.

  3.2 乙方应将出租房屋用作住宅用房。

  the leased property shall be used by part b for residential purpose.

  四、租赁期:

  term of tenancy:

  4.1 租赁期为_____年,自 年 月____日起至_______年____月____日止。

  the tenancy shall be for a term of years,commencing on ______________and expiring on __________________.

  4.2 租赁期满,如乙方不再根据此条款续约,甲方有权收回全部出租房屋,乙方应如

  期交换出租房屋予甲方。乙方如要求续租,须在本合同期满三个月前向甲方提出书面申请,再由双方另行续租事宜。

  on expiry of the tenancy, if party b has not exercised its option to renew this agreement in accordance with this clause,party a has the right to repossess the entire leased property,and party b shall deliver the leased property to the party a provided always that party b shall have the option to renew this agreement upon giving prior written novice to party a of its intention to do so that least three(3) months before the expiration of this agreement.

  五、租金:

  rent

  5.1 双方谈定的租金为每月____________________人民币,租金包括除水、电、液化气、电话费以外的一切管理费。

  the rent for the leased property as agreed to by both parties is rmb___________yuan per month, which rent includes all management fee.

  5.2 支付甲方壹个月的租金,应在每个月的第十天以前支付给甲方。

  party b pay the rental fee before the tenth day of every calendar one month.

  5.3 所有保证金、租金等费用均以人民币通过银行汇入甲方所提供的以下银行账户及户名:

  账号:____________________户名:______________开户行:____________________

  all payments of security deposit,rent fee,etc heteunder shall be made be made by bank transfer rmb to party a's following account.

  account no:________________________,user name:_____________bank:___ ________ __

  六、保证金:

  security deposit:

  6.1 为确保出租房屋及其设施之安全并完好及租赁期内相关费用之如期结算,乙方同意于签订合同10天内支付给甲方贰个月租金的`租赁押金计__________________人民币作为乙方确保合同履行之保证金。乙方搬入后十天内付壹个与租金计______________人民币。

  to ensure the protection and good condition of the leased property and the related facilities as well as the prompt payment and settlement of all related charges during the term of tenancy,party b agrees to pay to party a with 10 days when the execution of this agreement a security for party b’s obligations hereunder. when party b move in,party b pay one month’s rental in the amount of___________with 10days.

  6.2 除合同另有约定之外,甲方应于租赁期满或此合同提前终止之期且乙方透空、点清并付清所有应付费用后,当天将保证金全额无息退还乙方,如保证金以人民币支付,届时也应以人民币形式退还。

  unless otherwise provided in this agreement, party a shall return to party b the entire security deposit without interest thereon upon expiration or soonder detemination of this agreement provide that party b has vzcated the leased property and settled all related charges. if this security deposit was paid in rmb,it shall be returned to party b in the form of rmb.

  七、其他费用:

  other charges:

  乙方应承担租赁期内实际使用而产生的水、电、液化气费、电话费并按单自行如期交纳所属管理公司或有关机构。

  during the term of tenancy,party b is responsible for paying the charges in relation to water, electricity, gas,telephone charges on the basis of the amount of such utilities party b uses. such charges shall be paid when due according to the invoice therefore received by party b from the management company or relevant authority every month.

  八、甲方的责任:

  party a’s obligations:

  8.1 甲方须按时将出租房屋及其家私家具用品与其设施以良好状态交付乙方使用。

  party a shall deliver on schedule to party bvacant possession of the leased property including the furniture,furnishing and appliances and the related facilities for party b’s use(furniture,furnishing and appliances to be detailed in appendisl.)

  8.2 租赁期内甲方不得收回出租房屋(除非本合同另有规定),甲方保证乙方可不受干扰的享用该物业。

  party a shall not repossess the leased property during the term of party a disturb of interfere with party b’s quiet enjoyment of the leased property.

  8.3 在乙方遵守本合同的条款及支付租金的前提下,乙方有权于租赁期内拒绝甲方或其他人骚扰而安静享用出租房屋。

  proviede that party b pays the rent and performs and observes party b’s terms and conditions in accordavce with this agreement, party b shall be entitled to hold and enjoy the leased property throughout the term of this tenancy without any interruption by party a or any other person.

  8.4 租赁期内出租房屋的结构,进出物业的排水、上下管道、电路等处于良好使用状态。

  party a agrees to repair and maintain the structure,drains, pipes and cables, etc.leading in to or from the leased property at all times in good and tenable repair during the term of this tenancy.

  九、乙方的责任:

  party b’s obligations:

  9.1 乙方应按合同的规定,按时支付租金,保证金及其他各项应付费用。

  party b shall promptly pay all rent ,security deposit and other charges payable by it in accordance with the terms of this agreement.

  9.2 乙方应爱护使用出租房屋,如因乙方的过失或过错致使房屋设施及屋内用具和饰品受到损坏(正常损耗除外),乙方应负赔偿责任。

  paryt b shall treat the leased property with care. if as a result of party b’s negligence or misconduct, the leased property and the related facilities and accessorties suffer any damage(fair wear and tear excepted ),party b shall be responsible for compensating party a for such damages.

  9.3 乙方应按本合同的约定合法使用出租房屋,不得擅自改变使用性质,不应存放中华人民共和国法律下所禁止的危险物品,如因此发生损害,乙方应承担全部责任。

  party b shall use the leased property legally as agreed in this agreement and may not change such use on its own…party b shall not store any dangerous items which are prohibited by the laws in the people’s republic of china in the leased property and shall be fully responsible for any admages of losses as result thereof.

  9.4 未经甲方事先书面同意,乙方不得将出租房屋转租或租给其他的第三者。

  without party a’s prior written consent ,party b may not assign the tenancy or sublet the leased property to a third party.

  十、违约处理:

  breach of agreement :

  10.1 甲、乙任何一方如未按本合同的条款履行,构成违约,应承担相应的违约责任。双方同意违约方应赔偿守约方之直接损失人民币____________元。

  if either party a or party b fails to perform its obligations hereunder ,it shall constitute a breach of this agreement and the defaulting party shall be liable for the liabilities resulting from such breach. the parties agree that the party in breach shall pay the other party compensation ____________________for the direct loss and damage suffered by the other party as result of such breach .

  10.2 乙方有下列行为之一的,甲方有权终止本合同,收回出租房屋,并且保证金不予返还;

  party a shall have the right to terminage this agreement ,repossess the leased property and forfeit the security deposit if party b commits one of the following:

  a.未得甲方书面书面同意,将出租房屋擅自转租;

  sublets the leased property without party a’s written consent;

  b.未得甲方同意将出租房擅自拆改结构或改变用途的:

  alters the structure of the leased property or uses the leased property other than for the purpose started herein without party a’s consent;

  c.无故拖欠租金超过三天(除双方就本合同存在争议除外)。

  fails to pay rent without any reason for more than thirty (30)days after the due date except where there is a dispute in respect of this agreement.

  十一、适用法律:

  applicable law:

  本合同的成立,其有效性、结实、签署和解决与其他有关的一切纠纷均应受中国法律的管辖并依据中国法律解释。

  the formation of this agreement ,its validity,interpretation,executiong and settlement of any disputes arising hereunder shall be governed by and construed in accordance with the laws of the people’s republic of china.

  十二、争议的解决:

  dispute resolution:

  凡因执行本合同所产生的或与本合同有关的一切争议,双方应通过友好协商解决;协商不成,应提交中国国际经济贸易仲裁委员会,按其仲裁规则和中华人民共和国仲裁法进行仲裁。仲裁解决是终局的,对双方都有约束力。

  in the case of disputes arising over this agreement of any matters related hereto ,the parties shall negotiate in good faith to resolve such disputes.if such negotiation fails, the parties shall submit the dispute to arbitration by the china international economic and trade arbitration commission in accordance with its arbitration rules and the arbitration law of the people’s republic of china.the decision of the arbitration body is final and shall be binding on the parties hereto.

  十三、其他

  others:

  13.1 本合同如有未尽事宜,由甲、乙双方洽谈解决。

  if this agreement it unclear with respect to certain matters, the two parties shall discuss to resolve such ambiguities.

  13.2 本合同由中、英文写成,两种文本具有同等效力。

  this agreement is written both in the chinese and english languages.both versions shall be equally authentic.

  13.3 本合同经双方签字后立即生效,未经双方同意,不得任意终止或修改,本合同另有约定除外,本合同一式二份,甲、乙双方各执一份。

  this agreement shall become effective upon the signing thereof by the parties hereto an registration with the relevant authorities.save and except as provided in this agreement ,this agreement may not bye terminated or amended without the consent of both parties.there are two(2) originals of this agreement ,one for party a,one for party b.

  本合同于__________年 月_____日签订。

  this agreement was signed in __________________on ________________

  甲方: 乙方:

  partya: partyb:

  盖章: 盖章:

  seal: seal:

  地址: 地址:

  address: address:

  电话: 电话:

  telephone number: telephone number:

  传真: 传真:

  fax number: fax number:

英文合同 篇6

  为了提高员工英文水平,北京xx公司(下称“公司”)聘请xx先生(下称“教师”)作为英文教师教授口语。经双方友好协商,达成以下聘任协议:

  1、合同效力

  本合同自双方签字后自动生效。

  2、聘任期

  六个月

  3、课程安排

  课程按以下计划安排

  3.1 每周两次,每次90分钟。

  3.2 每周课程具体时间是: 周一 ____:____

  周四 ____:____

  4、 双方责任

  4.1 教师职责包括:

  a) 根据参考书系统化,条理化教课。

  b) 为提高英语听说能力推荐相应的磁带。

  4.2 公司提供教室及第5条所规定的工资。

  5、薪水

  在聘任期内,公司在每月月底支付教师工资,每节课按240元人民币(税后)。

  6、结束

  合同到期后,无须通知任何一方,将自动终止。如其中任何一方欲延长合同,须在合同期满前2周通知对方。

  invitation agreement

  in order to improve the english level of the staff of _____ (hereinafter referred to as the “company" as one part) invite mr. xx (hereinafter referred to as the ”teacher" as the other party) to teach oral english courses. on the basis of friendly negotiation, both parties enter into this invitation agreement:

  article 1 effectiveness of the agreement

  the agreement shall come into force automatically as of the signature date of this agreement.

  article 2 term of invitation

  term of invitation shall be ____ .

  article 3 schedule of courses

  the courses shall be arranged with the following schedule,

  3.1 2 courses per week, each course costs 90 minutes.

  3.2 for each week, the courses is allocated to

  monday ___: ___

  thursday ___: ___

  article 4 duties of the two parties

  4.1 the teacher shall perform in a diligent manner, including:

  a. formulate and provide a systematically teaching courses with reference books;

  b. recommend tapes if they are conducive to improve listening and speaking english.

  4.2 the company shall provide teaching room and pay salary to the teacher in accordance with article 5.

  article 5 salary

  during the term of invitation, the company shall pay the teacher an after tax salary at rmb _____ per course at the end of each teaching month (each 4 courses over).

  article 6 termination

  this agreement shall automatically terminate, without notice by either party to the other, when it expires. if one party wishes to extend this agreement, he shall notify the other party two weeks before the termination day of this agreement.

英文合同 篇7

  THIS AGREEMENT OF LEASE is made on this 16th day of December 20xxby and BETWEEN:

  Mrs. Ghazala Waheed w/o Abdul Waheed, Adult, R/o House No.***-*, DHA, Lahore Cantt, (hereinafter to as the LESSOR of the ONE PART).And Mr.* ***,R/o China, refereed to as the LESSEE of the OTHER PART.(Expression “LESSOR”and “LESSEE” wherever the context so permit shall always mean and include their respective heirs, successors legal representative and assignees).

  WHEREAS the LESSOR is the lawful owner and in lawful possession of House No,***-*,DHA,Lahore Cantt, consisting of 4 Bedrooms with bath, D/D,TV; Lounge, Kitchen, Store, Servant, Quarter together with fixtures and fitting (hereinafter collectively called the DEMISED PREMISES).

  AND WHEREAS the LESSOR has agreed the lease and the LESSEE has agreed to take on lease the DEMISED PREMISES on the terms and condition as given below:

  1. This agreement in only valid if LESSEE is renewed and extended for the lease period.

  2. The LESSOR lets LESSEE takes the DEMISSED PREMISES for a period of 12 months Commencing from 15th January 20xx. The Lease is renewable for a further period as may be mutually agreed in writing on expiry of the lease period

  3. The rent of the DEMISED PREMISES shall be USD3,300/-(US dollars Three Thousand and Three hundred Only) per month

  4. The LESSOR hereby acknowledges receipt of the sum of USD.19,800/-(US dollars Nineteen Thousand and eight Hundred Only) per month.

  5. It is hereby agreed between the parties that the LESSEE shall pay the aforesaid monthly rent

  USD. 3,300/-(US dollars Three Thousand and Three hundred Only) as the monthly rental advance by 20th of each calendar month for which if is due after completion of advance rent period ending on 15th July 20xx.

  6. That the LESSOR hereby acknowledges receipt of the sum of Rs.60,000/-(Rupees Sixty Thousand Only) from the LESSEE as FIXED EDPOSIT SECURITY which shall be refunded to the LESSEE on giving back the vacant possession of the DEMISED PREMISES after deduction of damages/shortages outstanding bills for Electricity, Water, Gas and Telephone charges etc, against the DEMISED PREMISES.

  THE LESSEE HERBY CONVENANTS WITH LESSOR AS FOLLOWING:

  To pay to the LESSOR the rent hereby reserved in the manner before mentioned.

  Signature: Signature:

  Stamp: Stamp:

  Date: Date:

英文合同 篇8

  一.hereby

  英文释义:by means of , by reason of this

  中文译词:特此,因此,兹

  用法:常用于法律文件、合同、协议书等正式文件的开头语;在条款中需要强调时也可用。

  语法:一般置于主语后,紧邻主语.

  例1:

  The Employer hereby covenants to pay the Contractor in consideration of the execution and completion of the Works and the remedying of defects therein the Contract Price or such other sum as may become payable under the provisions of the Contract at the time and in the manner prescribed by the Contract.

  参考译文:

  业主特此立约保证在合同规定的期限内,按合同规定的方式向承包人支付合同价,或合同规定的其它应支付的款项,以作为本工程施工、竣工及修补工程中缺陷的报酬。

  注释:

  (1)hereby: by reason of this 特此

  (2)covenant: v. make a formal agreement 立约,签订合同、条约; n. legal agreement具有法律约束的正式合同

  (3)completion of the Works: 工程的竣工

  (4)therein: in the Works在本工程中

  (5)the Contract Price: 合同总价,指工程的总造价

  (6)such...as: 关系代词,相当于that, which

  (7)under: in accordance with 根据,按照

  (8)the provisions of the Contract: terms and conditions of the Contract合同条款

  例2:

  We hereby certify to the best of our knowledge that the foregoing statement is true and correct and all available information and data have been supplied herein, and that we agree to provide documentary proof upon your request.

  注释:

  (1)hereby:特此

  (2)to the best of our knowledge:as far as we know据我们所知

  (3)foregoing statement:above-mentioned statement上述声明

  (4)herein:in this, in the statement在声明中

  (5)documentary proof:证明文件

  参考译文:

  特此证明,据我们所知,上述声明内容真实,正确无误,并提供了全部现有的资料和数据,我们同意,应贵方要求出具证明文件。

  例3:

  This Contract is hereby made and concluded by and between Co. (hereinafter referred to as Party A) and Co. (hereinafter referred to as Party B) on (Date), in (Place), China, on the principle of equality and mutual benefit and through amicable consultation.

  注释:

  (1)hereby:特此

  (2)hereinafter referred to as Party A:以下称甲方

  (3)on the principle of equality and mutual benefit:在平等互利基础上

  (4)through amicable consultation:通过友好协商

  参考译文:

  本合同双方, 公司(以下称甲方)与 公司(以下称乙方),在平等互利基础上,通过友好协商,于 年 月 日在中国 (地点),特签订本合同。

  例4:

  This agreement is hereby made and entered into on (Date), by and between Co. China (hereinafter referred to as Party A) and Co. (hereinafter referred to as Party B).

  注释:

  (1)this agreement is hereby made and entered into:特此订立本协议 在法律文件中表示“订立本协议”可用以下4个动词:sign (make, conclude or enter into) this agreement, 按照同义词连用的写作特点,可用上述4个动词中的两个来表示)。

  (2)hereinafter referred to as Party B:以下简称乙方

  参考译文:

  本协议特由中国 公司(以下简称甲方)与 公司(以下简称乙方)于 年 月 日订立。

  二 hereof

  英文释义: of this

  中文译词:关于此点;在本文件中

  用法:在表示上文已提及的.“本合同的、本文件的??”时,使用该词。例如表示本合同条件、条款时,可以说“the terms, conditions and provisions hereof”,这里hereof表示“of this Contract”;又如表示本工程的任何部分,可用“any parts hereof”,这里hereof表示“of this Works”。 语法:一般置于要修饰的名词的后面,与之紧邻。

  hereof和thereof的区别:hereof强调“of this”。例如,上面的“the terms, conditions and provisions thereof”中的thereof表示of the Contract;“any parts thereof”中的thereof表示of the Works。

  例1

  Whether the custom of the Port is contrary to this Clause or not, the owner of the goods shall, without interruption, by day and night, including Sundays and holidays (if required by the carrier), supply and take

  delivery of the goods. Provided that the owner of the goods shall be liable for all losses or damages including demurrage incurred in default on the provisions hereof.

  注释:

  (1) Whether the custom of the Port is contrary to this Clause or not:不论港口习惯是否与本款规定相反,whether? or not:不论??是否

  (2) the owner of the goods:货方

  (3) without interruption:无间断地

  (4) carrier:承运人

  (5) in default on the provisions hereof:违反本款规定 hereof:of this Clause

  参考译文:

  不论港口习惯是否与本款规定相反,货方都应昼夜地,包括星期日和假日(如承运人需要),无间断地提供和提取货物。货方对违反本款规定所引起的所有损失或损坏,包括滞期应负担赔偿责任。

  例2

  Foreign trade dealers as mentioned in this Law shall, in accordance with the provisions hereof, cover such legal entities and other organization as are engaged in foreign trade dealings.

  注释:

  (1) foreign trade dealers:对外贸易经营者

  (2) as mentioned in this Law:本法所称

  (3) the provisions hereof:the provisions of this Law 本法规定

  (4) legal entity:法人

  (5) be engaged in foreign trade dealings:从事对外贸易经营活动 参考译文:

  本法所称对外贸易经营者,是指依照本法规定从事对外贸易经营活动的法人和其他组织。

  例3

  The establishment of a limited liability company or a company limited by shares shall comply with the conditions and provisions of this Law. A company complying with the conditions and provisions hereof may be registered as a limited liability company or a company limited by shares. Provided that if a company fails to comply with the conditions and provisions hereof, the company in question shall not be registered as a limited liability company or a company limited by shares.

  注释:

  (1)a limited liability company:有限责任公司

  (2)a company limited by shares:股份有限公司

  (3)provisions hereof:本法规定 hereof: of this Law

  (4)may be registered as:登记为

  参考译文:

  设立有限责任公司、股份有限公司,必须符合本法规定的条件。符合本法规定的条件的,登记为有限责任公司或者股份有限公司;不符合本法规定的条件的,不

  得登记为有限责任公司或股份有限公司。

  例4

  If, as a result of withdrawal or any other reasons, an arbitrator fails to perform his duties as an arbitrator, another arbitrator shall, in accordance with the provisions hereof, be selected or appointed. 注释:

  (1) as a result of withdrawal or any other reasons:回避或者其它原因

  (2) arbitrator:仲裁员

  (3) the provisions hereof:the provisions of this Law 本法规定

  (4) be selected or appointed:选定或指定

  参考译文:

  仲裁员因回避或者其它(转 载于:wWw.cnboThwiN.cOM 博 威范文 网:协议书英文怎么写)原因不能履行职责的,应当依照本法规定重新选定或指定仲裁员。

  例5

  In the event of conflict between the provisions on arbitration formulated and prepared prior to the effective date of this Law and the provisions of this Law, the provisions hereof shall prevail.

  注释:

  (1) conflict:相抵触

  (2) prior to the effective date of this Law:本法施行前

  (3) the provisions hereof shall prevail:以本法为准 hereof:of this Law 参考译文:

  本法施行前制定的有关仲裁的规定与本法的规定相抵触的,以本法为准。 例6

  Where, in accordance with laws, the circumstance(s) specified in Article 15 and Article 16 of this Law is /are confirmed, the organization with compensatory obligations shall pay compensation in any of the circumstance in question.

  Where the claimant for compensation demands the confirmation of one of the circumstances specified in Article 15 and Article 16 hereof, and the demanded organization refuses to make the confirmation, the claimant shall have the right to lodge a complaint. Where the claimant claims compensation, the claim, shall, first, be lodged to the organization for compensatory obligations.

  The provisions of Article 10, Article 11 and Article 12 hereof shall apply to/ in the procedures of compensation.

  注释:

  (1) the organization with compensatory obligations:赔偿义务机关

  (2) shall pay compensation:应当给予赔偿

  (3) the claimant for compensation:赔偿请求人

  (4) Article 15 and Article 16 hereof:本法第十五条、第十六条 hereof:of this Law

  (5) shall have the right to lodge a complaint:有权申诉

  (6) claims compensation:要求赔偿

  (7) apply to/ in:适用 More Examples: The comment applies equally here. /That argument does not apply in this case. /That applies to at least nine-tenths of the people we see about. /These remarks apply to every town in this kingdom. /The rules of safe driving apply to everyone. 参考译文:

  赔偿义务机关对依法确认有本法第十五条、第十六条规定的情形之一的,应当给予赔偿。

  赔偿请求人要求确认有本法第十五条、第十六条规定情形之一的,被要求的机关不予确认的,赔偿请求人有权申诉。赔偿请求人要求赔偿,应当先向赔偿义务机关提出。赔偿程序适用本法第十条、第十一条、第十二条的规定。

  例7

  If an arbitrator involved in one of circumstances specified in Item 4, Article 34 of this Law, and if it is serious, or those specified in Item 6, Article 58 hereof, the arbitrator in question shall, in accordance with the law, bear the legal liability and responsibility. The arbitration commission shall remove the name of the arbitrator in question from the list of arbitrators.

  注释:

  (1) arbitrator:仲裁员

  (2) Article 58 hereof:本法第五十八条 hereof:of this Law

  (3) bear the legal liability and responsibility:承担法律责任

  (4) the arbitration commission:仲裁委员会

  (5) remove the name of the arbitrator in question from the list of arbitrators:将其除名

  参考译文:

  仲裁员有本法第三十四条第四项规定的情形,情节严重的,或者有本法第五十八条第六项规定的情形的,应当依法承担法律责任,仲裁委员会应当将其除名。 例8

  If, pursuant to this Law, the relevant responsible authorities with the duty of approvals fail to grant approval to such an application as meets the requirements and provisions hereof, or the company registration authorities fail to register a company whose application meets the requirements hereof, the party in question may, in accordance with laws, apply for reconsideration or bring an administrative suit.

  注释:

  (1) the relevant responsible authorities with the duty of approvals:履行审批职责的有关主管部门

  (2) meets the requirements and provisions hereof:符合本法条件

  (3) the company registration authorities:负责公司登记的主管部门

  (4) the requirements hereof:本法条件 hereof: of this Law

  (5) apply for reconsideration:申请复议

  (6) bring an administrative suit:提起行政诉讼

英文合同 篇9

  技 术 合 作 协 议

  Technical Cooperation Agreement

  甲方:XX油脂化学有限公司

  Party A: XX Grease Chemical Co. , Ltd.

  地址: XX高新技术工业园

  Address:XXHigh-tech Industrial Park

  法定代表人:XXX

  Legal Representative: XXX

  乙方:

  Party B:

  地址:

  Address:

  本协议合作双方就组建技术研发团队事项,经过平等协商,在真实、充分地表达各自意愿互惠互利的基础上,根据《中华人民共和国合同法》的规定,达成如下协议,并由合作各方共同恪守。

  This Agreement, concerning the setting up of a technical research and development team, is made according to the Contract Law of PRC regulations and entered into through equal negotiation by both Parties as the free and full expression of their own wishes to mutual benefits, and to this end both Parties shall abide by this Agreement as following.

  第一条、 甲方同意雇用乙方为新产品研发技术顾问。乙方同意为甲方提供技术

  顾问服务。

  Article 1: Party A hereby agrees to employ party B as the technical consultant for the new product research and development. Party B hereby agrees to offer technical consultation service to Part A.

  第二条、 甲方同意每月支付乙方的研究费用,包括:薪资、办公费、检测费、

  差旅费以及其他相关费用。

  Article 2: Party A hereby agrees to pay Party B for the research each month, including salaries, administrative expenses, detection cost, traveling expenses and other cost associated.

  第三条、 乙方有责任为甲方提供相关国内外技术及市场信息,并及时答复甲方

  技术上所遇到的问题。

  Article 3:Party B is responsible to provide relevant technical and market information home and abroad and is ready to answer any technical problem frequently asked by Party A.

  第四条、 乙方有义务向甲方提供有关个人简历和相关证明材料,甲方要尊重乙

  方个人隐私,有义务妥善保管相关材料。

  Article 4: Party B shall has the obligation to provide Party A with any relevant personal resume and reference documents as necessary. Party A shall respect the personal privacy of Party B and has the obligation to properly keep those materials.

  第五条、 乙方同意所研发的'产品所有知识产权归甲方所有,乙方不得将相关技

  术信息泄露给任何第三方,否则需要承担一切法律后果。

  Article 5: Party B hereby agrees that the intellectual property of any product as researched and developed herein shall be owned by Party A. Party B shall not be allowed to disclose any technical information concerned to the third party, or it shall take all the legal consequences.

  第六条、 甲乙双方同意通过紧密合作达到共同目标;每年增加一到三个项目;

  每年申请一到三个发明专利;每年完成一到两个能够通过专家认证的

  新产品;每年至少向市场推广两个产品。

  Article 6: Both Parties agree to achieve their common goals by their close cooperation. It is planned to add one to three projects each year and to apply for one to three patents for inventions each year, to make one to two new products certified by experts each year, and to promote at least two products to the market each year.

  第七条、 此协议甲乙双方各执一份,没有在协议中提到的事项双方需协商解决。 Article 7: This Agreement is held by both Parties, one for each respectively. Any issue not mentioned in this Agreement shall be settled by both Parties through negotiation.

  此协议从签字当日起生效。

  This Agreement shall take effect from the date of signature.

  甲方:乙方:

  Party AParty B:

  签字:签字:

  Signature: Signature:

  日期:日期:

  DateDate:

【英文合同】相关文章:

英文翻译合同03-02

买卖合同英文01-30

精选英文合同四篇04-25

英文合同集锦五篇04-26

英文合同集锦六篇04-26

实用的英文合同3篇04-26

【必备】英文合同三篇04-25

英文合同合集7篇04-27

【精华】英文合同四篇04-28

【实用】英文合同三篇04-29